CIAP Document 102

Question 1

CIAP

Answer 1

Construction Industry Authority of the Philippines

Question 2

CIAP Document 102 is also known as

Answer 2

Uniform General Conditions of Contract for Private Construction

Question 3

CECOPHIL

Answer 3

Council of Engineering Consultants of the Philippines

Question 4

CPMAP

Answer 4

Construction Project Management Association of the Philippines

Question 5

CREBA

Answer 5

Chamber of Real Estate and Builders Association

Question 6

IFBWW

Answer 6

International Federation of Building and Wood Workers

Question 7

PCA

Answer 7

Philippine Constructors Association, Inc.

Question 8

PCCI

Answer 8

Philippine Chamber of Commerce, Inc.

Question 9

PICA (now PICAM)

Answer 9

Philippine Institute of Construction Arbitrators (now Philippine Institute of Construction Arbitrators and Mediators)

Question 10

PICE

Answer 10

Philippine Institute of Civil Engineers

Question 11

SHDA

Answer 11

Subdivision and Housing Developers Association of the Philippines

Question 12

UAP

Answer 12

United Architects of the Philippines

Question 13

SPAC

Answer 13

Society of Philippine Accredited Consultants

Question 14

COFILCO

Answer 14

Confederation of Filipino Consulting Organizations, Inc.

Question 15

Implementing arms of the CIAP

Answer 15

Philippine Domestic Construction Board (PDCB) and the Philippine Overseas Construction Board (POCB)

Question 16

It contains terms and conditions ordinarily established in construction contracts. It is intended for use in contracts for private construction in the Philippines.

Answer 16

CIAP Document 102

Question 17

A typical Construction Contract consists of

Answer 17

Agreement, General Conditions, Drawings, Specifications, and other documents

Question 18

Is used to describe the combination of two (2) sets of documents: the Agreement and the Contract Documents

Answer 18

Contract

Question 19

Is used to describe the agreement signed by the Owner and the Contractor, excluding the Contract Documents

Answer 19

Agreement

Question 20

Are attached to the Agreement identified therein

Answer 20

Contract Documents

Question 21

Contract Documents generally include the following

Answer 21

Special Provisions or Conditions; General Conditions; Specifications; Drawings; and other Bid Documents

Question 22

Are instructions which are issued prior to bidding to supplement and/or modify the Drawings, Specifications and/or General Conditions of the Contract

Answer 22

Special Provisions or Conditions

Question 23

Are the written or printed description of the work to be done describing qualities of the material to be used, the equipment to be installed and the mode of construction

Answer 23

Specifications

Question 24

Are graphical presentations of the Work, including supplementary details and shop drawing

Answer 24

Drawings

Question 25

Pertain to the roles, rights and obligations of the contracting parties, and the rules and procedures by which the parties and everyone concerned will be able to meet their obligations and perform the Works covered under the Contract

Answer 25

General Conditions of Contract

Question 26

The Owner, with the Contractor’s assistance, shall secure and pay ___ construction permits and licenses necessary for the execution of the Work.

Answer 26

all

Question 27

The Contractor shall secure the ___ but he shall not be responsible to the Owner if, without his fault, the license is not issued or there was delay in its issuance.

Answer 27

Final Occupancy Permit

Question 28

The Contractor shall pay ___ taxes as required by Laws pertinent to the construction of the project. Who is in charge of the safety an

Answer 28

all

Question 29

_____ provides that it is the obligation of the _____ to protect the work and the Owner’s property from damage.

Answer 29

Section V (Protection of Work and Property), Contractor

Question 30

What are the bonds and guarantees required of the Contractor?

Answer 30

1. Contractor’s Liability Insurance 2. Accident Insurance for Workers 3. Contractor’s Fire Insurance 4. Contractor’s Performance and Payment Bonds 5. Contractor’s Guarantee Bond 6. Contractor’s Guarantee-Warranty

Question 31

Article 32.02 states that the Owner may ___ to obtain an insurance that will protect him from his contingent liability.

Answer 31

opt

Question 32

Mean a period of not more than thirty (30) calendar days, calculated from the date of receipt by the Contractor of the last item in the punch list

Answer 32

“Period of Making Good of Known Defects”

Question 33

When the Contractor completes ninety five percent (95%) of the Work

Answer 33

Substantial completion

Question 34

list of defects found or discovered on the completed work and which should be received by the Contractor not later than 30 days from date of substantial completion

Answer 34

Punch list

Question 35

CIAC

Answer 35

Construction Industry Arbitration Commission

Question 36

Tasked to provide alternative dispute resolution facilities for the speedy and equitable settlement of claims and disputes arising from, or connected with, construction contracts in the Philippines

Answer 36

CIAC (Construction Industry Arbitration Commission)

Question 37

Mean a voluntary process in which a mediator, selected by the disputing parties, facilitates communication and negotiation, and assists the parties in reaching a voluntary agreement regarding a dispute

Answer 37

Mediation

Question 38

Defined as the investigation and determination of matters of differences between contending parties by one or more unofficial persons, called arbitrators or referees, chosen by the parties

Answer 38

Arbitration